Procurement & Contract Services

Size: px
Start display at page:

Download "Procurement & Contract Services"

Transcription

1 UNIVERSITY OF ALASKA FAIRBANKS Procurement & Contract Services E-Solicitation REQUEST FOR PROPOSAL (RFP) NO. 12P0010RD TITLE OF SOLICITATION: UAF Electrical Supervisory Control and Data Acquisition System (SCADA) The University of Alaska is requesting proposals to contract for an Electrical SCADA System and Electric Power System Arc Flash, Short Circuit, Fault Analysis and Coordination Study. OR DELIVER PROPOSALS TO: For Delivery of electronic media: University of Alaska Fairbanks Procurement & Contract Services 3295 College Rd, Rm 103 Fairbanks, AK For PRE-PROPOSAL CONFERENCE: Friday, December 2, AM DEADLINE FOR QUESTIONS: December 8, 2011 PROPOSALS MUST BE RECEIVED NO LATER THAN: December 16, :00 PM. Alaska Time (FAX PROPOSALS WILL NOT BE ACCEPTED) SUBMITTAL DEADLINE ISSUE DATE: November 23, 2011 NOTE: Faxed, telegraphed proposals, or proposals submitted by means other than those indicated on the Electronic Signature Page are not acceptable and shall be rejected as non-responsive. NOTICE TO OFFERORS: POINT OF CONTACT FOR RFP INQUIRIES: Rick A. Danielson, Contracting Officer rick.danielson@alaska.edu Phone: Fax: MAILING ADDRESS: University of Alaska Fairbanks Procurement & Contract Services 3295 College Rd, Rm 103 Fairbanks, AK The person designated above in this notice shall be the only contact for all inquiries regarding any aspect of this RFP or its requirements. Offerors who seek or receive information regarding this solicitation from any University official other than those listed above may be declared non-responsive and removed from further consideration. A copy of this solicitation, support documents and any amendments issued shall be accessed from the UAF Procurement and Contract Services Website at the following starting link: AVAILABILITY OF FUNDING: A contract resulting from this RFP shall only be issued subject to the availability of funding. The funding source allows or does not allow application of Alaska preference laws. PROCUREMENT OFFICER: Rick A. Danielson, Contracting Officer

2 RFP Support Document E-Signature Form University of Alaska Fairbanks Electronic Signature Page The following sections are integral to this solicitation and have legal implications. Signature indicates agreement and/or compliance with all marked sections. Any exceptions must be indicated on the Statement of Compliance Form. Vendors may be declared non-responsive for failure to comply and respond appropriately. Solicitation Support Documents & Checklist of Required Submittals: Marketing Group Legal/Risk Group Administrator Group Cover Instructions to Offerors Proposal Transmittal Form RFP Document Modified Insurance Statement of Compliance Electronic Signature Special Conditions or Representations & Certifications Project Specific Requirements Award Contract Non Personal Services Contract Professional Services Contract Instructions-The groups are linked to website access for documents to be downloaded and reviewed by the appropriate authority. Complete all forms and submit (PDF) with your proposal in the order indicated below. Combine the files in an organized manner so that an offer will consist of two files. Send questions immediately to the responsible procurement officer noted on cover page. Special or project specific requirements Order documents for submittal in the following manner: Save all of your documents as one Adobe PDF file with a separate rate sheet PDF. Offers will be received in the following format(s): USB Flash Memory CD or DVD radanielson@alaska.edu Preparer signature:... i Please list Company Name and staff member (with authority) that reviewed documents: Company Date Name Date Signature Date i Bidders/Offerors agree by submittal of their bid or offer by electronic means that: and fax responses may not be as secure or confidential as if delivered or mailed in a sealed envelope; The risk of busy signals or delayed transmissions, especially as the submittal deadline approaches, is substantial; Electronic responses must include all required pages, and information and shall be received in its entirety prior to the submittal deadline; An Incomplete electronic response, or a response not received in its entirety prior to the submittal deadline are late and shall be rejected as untimely; That no accommodation will be made for receipt of electronic responses that are late due to busy phone lines and networks, malfunction of the fax machine of either the sender or receiver, equipment incompatibility, or delays in transmission, and that rejection of a bid due to the above causes is not grounds for protest; The bidder bears sole responsibility for follow-up to ensure that the entire document has been received timely.

3 UAF ELECTRICAL SCADA SYSTEM: THE UNIVERSITY OF ALASKA FAIRBANKS (UAF) IS SOLICITING PROPOSALS TO ESTABLISH A CONTRACT FOR AN ELECTRICAL SCADA SYSTEM AND SERVICES. THE SUCCESSFUL OFFEROR SHALL FURNISH A COMPLETELY DESIGNED, TESTED, INSTALLED, COMMISSIONED SCADA SYSTEM FOR THE ELECTRIC POWER SYSTEM IN STRICT ACCORDANCE WITH THE SPECIFICATIONS, PROVISIONS, AND TERMS & CONDITIONS OF THIS REQUEST FOR PROPOSAL. UNIVERSITY OF ALASKA FAIRBANKS RFP NO.12P0010RD ELECTRONIC SUBMITTAL PROCESS The University of Alaska Fairbanks, Procurement and Contract Services Division is modifying the solicitation process to better serve clients, vendors, and staff in the following manner: match the current business process by leveraging web services and availability reflect the way vendors do business in response to a solicitation by parsing sections out to staff members by functional area save on resources including staff and vendor preparation time enhance communication bolster competition The current document describes the project. The solicitation is complemented by a number of support documents that are identified in the checklist on the electronic signature page. Any strikethroughs of text shall indicate that the term or condition does not apply to this solicitation. ACTION PLAN: Vendors may download, review, and print sections at their option. The documents are organized into three groups. -links to one document that outlines the purpose of the proposal with specification or statement of work details, evaluation criteria, and the rate response form (this document). Legal/Risk Group II-links to a contract document, general provisions, statement of compliance, and special conditions (if applicable). Administrator Forms Group III-links to several forms for completion; transmittal, cover, electronic signature, representation and certification documents. The groups are to be downloaded and reviewed by the appropriate authority. Administrative staff may prepare, print, and distribute the support documents to staff members with the appropriate expertise. Make a special note of documents that require signature and must be submitted with an offer. The documents and offer shall be assembled in the proper order and combined into a single PDF. This will be accompanied by a second PDF file with the vendor s rate response information. The University website provides access to all support documents, opens communication, and facilitates a team response to a solicitation.

4 COPIES OF OFFICIAL DOCUMENTS Offerors may request an MS Word copy of the RFP documents to include all forms that require a response and submittal. The University of Alaska Fairbanks, Procurement & Contract Services, Administrative Policy indicates the following: "This solicitation is provided as an MS Word document in order to allow offerors the ability to more easily prepare a response to the RFP. The offeror may not add, delete, or alter any language provided by the University in the solicitation. In the event that there is any difference between the language contained in the MS Word version of the solicitation and the Adobe pdf version located on the UAF Procurement website, the language on the website prevails." PURPOSE OF SOLICITATION PROJECT: The University of Alaska Fairbanks (UAF) is seeking responses to this request for proposal (RFP) for engineering, design, and field support Services related to the best overall proposed design, supply and commissioning of hardware and software for an Electrical Supervisory Control and Data Acquisition System (SCADA), and other services related to the commissioning of the newly installed 12kV switchgear for the Critical Electrical Distribution Renewal Project. University of Alaska Fairbanks (UAF) will enter into a contract with a highly qualified hardware and software vendor whose prime business is to provide electrical control and monitoring system technology for an Electrical SCADA System and supporting services as determined by the evaluation methods of this RFP. The vendor shall be referenced as SCADA Vendor/Contractor (SVC) or Contractor within this RFP. The Electrical SCADA project consists primarily of the following: Establish a contract with a SVC for fixed price supply of design, hardware, software and services to provide a campus wide electrical SCADA system and electric power arc flash, short circuit, fault analysis, and coordination study that will provide UAF with the best overall solution for monitoring and control. (Note: Installation of cabinets, communication wiring and other fixed equipment will be done by UAF under the supervision of the SVC The following provides brief overview of the scope of work, which can be referenced in Summary of Work in the specifications, and technical specifications. Provide an electric power system Arc Flash, short circuit, fault analysis and coordination study Provide a detailed issue for construction design package for the SCADA System along with the Fiber Optics communication network. The design package shall contain a complete bill of material that UAF as desired can utilize for their onsite General Contractor (Kiewit Building Group - KBG) to install the design. Provide all labor and material to successfully complete the design, supervise installation, programming, configuration, testing, commissioning, training, and documentation and provide a turnover package for Electrical SCADA System 2 P age

5 Perform electric power system relay settings, testing and commissioning of the electric power system. The SVC is responsible for providing a complete and accurate fixed price proposal to complete the project as outlined in this RFP and per UAF s scope and specifications by June 30 th, An uninterrupted Campus wide electrical service is required to support continuous operation of the University, and performance as specified is critical to UAF operations. UAF Utility Operations - NOTE: For the purposes of this solicitation, the terms Offeror and SVC refer to the same entity. Generally, the term offeror will be used to refer to a vendor who submits a proposal and the term Contractor will be used to refer to the successful Offeror to whom award is made. ANTICIPATED SOLICITATION SCHEDULE: Issue Date 11/23/2011 Pre-Proposal Conference and Site Inspection..12/02/2011 Offeror Question Deadline..12/08/2011 Submittal Deadline..12/16/2011 Estimated Award Notification 01/10/2012 Estimated Contract Award Date....01/24/2012 Required Project Completion...06/30/2012 NORTH AMERICAN INDUSTRY CLASSIFICATION SYSTEM (NAICS) CODE: NAICS CLASSIFICATION NAME: Electrical Generating and transmission Equipment Repair and Maintenance Services In order to qualify as a small business for this solicitation, the business receipts of the concern and its affiliates during the preceding twelve (12) month period must not exceed $7 million. BASIS OF AWARD - SOURCE SELECTION Award will be made, pending availability of funding, to the responsive, responsible Offeror whose proposal receives the highest total number of evaluation points, price and other factors as outlined herein. The services to be performed are essential to the operation of the University, and the offeror s ability to perform these services on a daily basis will be a prime determining factor in the award of a contract. The University reserves the right to make award to other than the lowest price Offeror without conducting negotiations. Likewise, the proposal with the top technical ranking may not necessarily receive the award. Proposals that are unrealistic or offerors not having the ability to demonstrate adequate experience, equipment, capacity, or lack the comprehension of the scope may be rejected as non-responsive. 3 P age

6 UAF intends to evaluate proposals and make award without discussions with offerors. However, UAF reserves the right to conduct discussions if the Procurement Officer later determines them to be necessary. Proposals shall be subjected to an evaluation process consisting of a preliminary evaluation of administrative compliance followed by a technical evaluation of proposal content. The administrative evaluation will be performed by UAF Procurement & Contract Services. The technical evaluation will be performed by a committee of qualified UAF personnel. If both administrative and technical evaluation are deemed responsive, and achieve the minimum technical score required, the sealed pricing pages will be opened and scored to determine the overall highest evaluation point total by the Contracting Officer of UAF Procurement & Contract Services. PRE-PROPOSAL CONFERENCE There is a non-mandatory pre-proposal conference scheduled for the benefit of potential Offerors as follows: Beginning at 9:00 a.m., Friday, December 2, 2011 at UAF Division of Design & Construction, 590 University Ave., Fairbanks, AK. Audio conferencing will be available for Offerors. Audio conference participants should call the network just prior to conference time at (800) Enter Participant PIN # , and the network will allow immediate access to the teleconference. The purpose of the pre-proposal conference is to discuss the terms and conditions, specifications, and required submittals of this RFP. Offerors are provided the opportunity to ask questions and UAF the ability to provide clarifications. Offerors are asked to review the RFP thoroughly prior to the preproposal conference in order to facilitate a productive meeting. Submitting questions and/or comments in writing prior to the meeting is encouraged. Such questions or comments may be mailed ( is acceptable) to the RFP submittal address on the Cover Sheet or faxed to UAF Procurement & Contract Services at (907) , Attn: Rick Danielson, or the preferred method, at: radanielson@alaska.edu No changes to any terms, conditions, or requirements of the RFP will be made at the pre-proposal conference. No statements of any UAF representative, or information contained in the pre-proposal conference, if obtained by the Offeror, shall be relied upon as changing the language or intent of the RFP. Changes, if any, shall be issued in the form of a written amendment only. It is the sole responsibility of the Offeror to ascertain that all amendments have been received prior to the RFP submittal deadline. Notification of amendments shall be posted on the UAF Procurement website, and all registered parties will be notified when an amendment has been issued. UAF will conduct a limited site inspection for all attendees immediately following the pre-proposal conference. The site inspection will be led by one or more UAF representatives. The purpose of the site inspection is to allow potential Offerors the opportunity to familiarize themselves with the on-site conditions, lay-outs, routes, and other information which may be deemed useful in the preparation of Offerors proposal. The site inspection will show sample typical facility locations, but may not include all 4 P age

7 locations. UAF s representative(s) will be available to answer general questions about the facilities, usage, etc., but shall have no authority to amend, modify, enhance, or diminish the requirements of the solicitation. Attendance at the site inspection is not mandatory, however, failure to attend either the pre-proposal conference or the site visit may not be raised as a defense by an Offeror for any information which could have been known by attending. PERIOD FOR ACCEPTANCE OF PROPOSALS The proposal shall remain valid for at least ninety (90) days after the submittal deadline for receipt of proposals except as otherwise specified elsewhere in this solicitation. CONTRACT KIND & TYPE The contract awarded as a result of this solicitation shall be a fixed price, non-personal services contract for the Electrical SCADA project and related services as specified herein. The proposed rates will include all management, supervision, personnel, supplies, equipment, deliverables, support, travel, lodging, transportation, incidentals, and labor associated with providing the services listed herein. CONTRACT TERM Any Contract resulting from this solicitation shall be for the period from approximately January 24, 2012 through June 30, 2012 including all deliverables, final testing, and acceptance. This completion date is a time sensitive date, and failure to meet it may result in the application of liquidated damages as described herein. LIQUIDATED DAMAGES Liquidated damages associated with not meeting the contract term and delivery date for all work and deliverables required, including testing and acceptance, shall be charged against the Contractor beginning the first calendar day after the contract term end date. The amount of $4, per day will be assessed for each day until completion and acceptance are achieved. The assessment amount is the actual additional costs incurred if the MV distribution system is in-operable. This amount will be deducted from final payment to the Contractor. The amounts of these deductions are to cover estimated expenses to UAF as a result of the Contractor s failure to complete the work within the time specified. Such deductions are liquidated damages and are not to be considered as penalties. PAYMENTS & INVOICING Progress payments may be allowed under this contract. The contractor will be allowed to invoice on a monthly basis for an amount not to exceed 75% of the current contract scope completion percentage at the time of invoicing. Contractor shall submit a schedule of values 14 days after Contract award for UAF approval to support progress payment requests. UAF shall withhold for final payment, 20% of the contract price until all deliverables, testing, and acceptance are completed. Final payment shall be made on a net 15 basis. 5 P age

8 Standard invoice format will be determined and agreed upon by the Contract Administrator and the Contractor. The standard format shall be incorporated into the contract award and must be submitted in the same fashion for each billing period. AUTHORITY The Procurement Officer whose name appears on the cover sheet of this solicitation has statutory authority to act as agent for UAF. The Offeror is cautioned that instructions contrary to the provisions of this contract, which are received from UAF employees not specifically delegated authority to act in this matter, are not valid or binding on UAF, and are a violation of Alaska Statute and University of Alaska Regulations. QUESTIONS RECEIVED PRIOR TO THE DEADLINE FOR RECEIPT OF PROPOSALS All questions shall be directed to UAF Procurement and Contract Services (Attn: Rick Danielson). There are generally two types of questions. One requires directing the questioner to the specific section of the RFP where the answer may be found. At the option of the University, responses to these questions may be given over the telephone; such questions and answers are unofficial and in no case may an oral response to a question affect any aspect of this RFP process. The second type of question involves clarifying or interpreting parts of the RFP or the intent of the RFP. While the University has no obligation to respond to such questions, this type of question, and any response, shall be made in writing. Any written responses conveying material information shall be provided to all recipients of the original solicitation. If any oral responses are given, or claimed to be given, no person may rely upon them and they will not affect any aspect of this RFP. Offerors who seek or receive information regarding this solicitation from any University official other than those listed above may be declared non-responsive and removed from further consideration for award. Offerors questions and any University answers will become public records. Written questions must be submitted to UAF Procurement and Contract Services, 3295 College Road, Suite 103, Fairbanks, AK 99709, faxed to (907) (Attn: Rick Danielson), or ed to rick.danielson@alaska.edu. APPROVAL OF CONTRACTOR PERSONNEL The University reserves the right to approve or reject the use of any personnel used by the Contractor in the performance of any contract(s) issued as a result of this solicitation without prejudice. The Contractor shall provide up-to-date name(s) and telephone number(s) of point(s) of contact for use by UAF personnel in service matters at all times. PERFORMANCE AND PAYMENT BONDS The successful Offeror will be required to post a Performance Bond and Payment Bond in order to ensure performance. Within fifteen (15) days after issuance of the Notice of Intent to Award (NOITA), and prior to commencement of services, the Contractor shall deliver to UAF Procurement & Contract Services a Performance Bond and a Payment Bond for the protection of all persons supplying labor 6 P age

9 and/or material to the Contractor, satisfactory to UAF, and executed by a surety listed in the US Department of the Treasury s Listing of Approved Sureties (Department Circular 570), updated July 1, 2006 (available via internet at or the most recent update, and authorized to do business in the State of Alaska, in an amount equal to fifty percent (50%) of the Total Amount submitted on the Rate Response Form. These bonds shall remain in effect, in the amounts stipulated, at all times during the life of the contract. Cash or Letters of Credit in lieu of bonding are not permitted. Lapse of bonding shall considered a breach of contract, and the contract may be terminated for default and UAF shall be entitled to reprocurement costs and damages afforded by law. If UAF terminates the contract for default, the bonding company shall be responsible for performance of the remaining term of the contract. SUBCONTRACTING Offerors may use subcontractors to provide services required for contracts awarded as a result of this solicitation. UAF reserves the right to approve all subcontractors employed in the performance of the contract(s). All subcontractors and their employees shall be held to, and must meet the same standards and requirements of the contractor and the contract specification. If subcontractors are going to be proposed, offeror shall provide the subcontractors qualifications for evaluation as part of the proposal, especially if the subcontractor is providing expertise, products, or services essential to any component of the project. ( CONFIDENTIALITY & PROPRIETARY INFORMATION All companies receiving this RFP are required to keep all data strictly confidential. Failure to do so will result in elimination of the Offeror from consideration for award and in possible litigation. Proposals shall clearly indicate any information which is of a proprietary nature. Proprietary information must be limited to confidential information as defined in Instruction to Offerors (Public Information). Proposals will become public information after award of this RFP, in accordance with Alaska law. Once submitted, all proposals become the property of the University. EVALUATION AND AWARD GENERAL: All proposals shall be subjected to an evaluation process consisting of a preliminary evaluation of administrative compliance followed by a technical evaluation of proposal content. The administrative evaluation will be performed by UAF Procurement & Contract Services. The technical evaluation will be performed by a committee of qualified UAF personnel. At the discretion of UAF, interviews may be scheduled with the top Offeror that will consist of clarification and best and final offer. Price evaluation and scoring will be done by the Contracting Officer at the completion of the Technical Evaluation Committee scoring. 7 P age

10 ADMINISTRATIVE EVALUATION: All proposals will be evaluated to determine that they are responsive to the administrative and submittal requirements of the RFP. Proposals will be reviewed based on the following criteria: The proposal was received on time. The correct number of files were submitted with all documents in designated order (one file of the technical proposal and one Rate Response Form submitted as indicated on the Electronic Signature Page). The proposal was submitted in the correct format. All other necessary forms were included. Proposal forms were properly signed. All material alterations or erasures, if any, were initialed by signer of the proposal. UAF must be satisfied that the Offeror has a current business license in the State of Alaska with licensing and certification(s) to do the business required in this proposal. Technical minimum requirements as outlined in specifications. This evaluation will be performed by UAF Procurement & Contract Services. Proposals failing to comply with all administrative requirements may be declared non-responsive and removed from further consideration. TECHNICAL EVALUATION (WEIGHTED 60%) All proposals meeting the administrative requirements of the RFP will be forwarded to the evaluation committee. Non-price, technical evaluations shall be completed for each proposal, independently, by each member of the Committee, with no initial attempts being made to reach a scoring consensus. The Committee may discuss the details and features contained in an offer for the purpose of ensuring there is agreement about what is contained in an offer and/or to clarify parts of an offer which may be unclear. For this solicitation the technical evaluation shall consist of evaluating the offeror s submittals in response to the evaluation criteria as follows, total of 600 points: 1. Contractor Qualifications (weight 15%) 2. Methodology, Efficiency, Comprehension, and Schedule (Best Solution, Clarity, and Completeness) (weight 45%) Specification and Forms: SCORING METHODOLOGY: Non-Price: Proposals will be evaluated on non-price criteria as follows. Each member of the Committee will independently enter a scaled rating for each criterion outlined below. The scaled rating will then be multiplied by the weight to produce a weighted score for each factor. The weighted scores of all non-price factors will then be summed to provide a total weighted technical score for each proposal from each evaluator. The aggregate score of each proposal will then be divided by the number 8 P age

11 of evaluators to produce an average non-price technical score for each proposal. The highest number of technical points attainable is 600. If an offer fails to earn an average non-price technical score of 400 points, the offer may be found non-responsive and removed from further consideration for award. Upon completion of the non-price evaluation, discussions, requests for clarifications, or negotiations (without divulging competitors pricing, or standing) may be conducted with all qualified offerors, or those offerors who fall into a clear competitive range. Based upon the results of the scoring the University may seek clarifications from all offerors in the competitive range. The competitive range shall include all offers receiving both an average minimum score of 400 points in the technical evaluation AND, in sole discretion of the procurement officer, achieving a technical score high enough to remain under consideration for award when ranked with other offers received. This is not a strict mathematical formula and may not be challenged on that basis except in the case of obvious arithmetic errors. After the establishment of the competitive range the Procurement Officer will ensure that the opportunity to clarify, confirm, or otherwise respond to questions is provided to all offerors under consideration for award. This process will be sufficiently formal to ensure equity among offerors, and will be fully documented. If, during discussions, there is a need for any substantial clarification of, or change in the RFP, an amendment will be sent to all interested parties. Requests for substantial clarification, and/or any amendments are valid only if issued in writing by the responsible Procurement Officer. General questions shall be directed to all offerors. However, questions which pertain only to a particular proposal shall be sent only to that offeror. Offerors who fail to respond with the required information by the deadline stipulated, or who fail to adequately support apparent discrepancies, imbalances, or disproportionate submittals, may be declared non-responsive. Upon receipt of clarifications, the Committee may adjust each offeror s score, if necessary, to reflect any new information. Should it be necessary, as a result of additional information obtained during this clarification process, to amend the RFP, a written amendment may be issued. ORAL PRESENTATIONS During the evaluation process, the Committee may, at its discretion, request that all offerors in the competitive range make oral presentations. Such presentations will provide offerors with an opportunity to answer questions the Selection Committee may have regarding their proposal. Not all offerors may be asked to make such oral presentations. UAF reserves the sole right to determine the number of offerors included in the competitive range. BEST AND FINAL OFFER UAF reserves the right to request clarifications and request a best and final offer (BAFO) from each Offeror within the competitive range. However, UAF reserves the right to make award based exclusively on the submitted proposals without seeking a BAFO. 9 P age

12 PRICE EVALUATION After the non-price technical evaluation is completed, the sealed Rate Response Forms shall be opened by the responsible UAF Procurement Officer. Points will be assigned to each offeror s proposal based on the prices offered in accordance with the scoring methodology outlined herein. The scores given to each proposal for price are not subjective in nature; the proposal with the lowest price shall be assigned the maximum price score and proportional scores will be assigned to the other proposals. PRICE (WEIGHTED 40%) Price shall not be disclosed to the members of the evaluation committee until the technical evaluation process is completed. Points for price will be calculated by the Procurement Officer, based upon the pricing information submitted by each Offeror on the Rate Response Form, as follows: The Alaska Bidders Preference shall be applied to the price, where applicable. The maximum number of points allowable for price shall be given to the responsive, responsible proposal with the lowest evaluation total for price. (For purposes of this RFP, this number is 400.) Price points for the remaining proposals shall be calculated as follows: (a) multiply the lowest priced proposal price by the assigned weight for price. Divide that number by the price of each higher priced proposal. This produces a mathematically proportional assignment of price points. See the example below: (1) Offer A is $450,000, Offer B is $490,000, Offer C is $515,000. Therefore, (2) Assume Price is given a weight of 40. Offer A receives 400 points. (3) Offer B s price points are calculated as follows: $450,000 x 400 = 367 (rnd) Price points for B $490,000 (4) Offer C s price points are calculated as follows: $450,000 x 400 = 349 (rnd) Price points for C $515,000 (b) If additional rounds of price competition are required, the steps above are repeated for each subsequent price submittal. FINAL SCORE AND AWARD The Procurement Officer shall reconcile each evaluation form for the proper procedures, consistency, mathematical extensions, and totals. The Procurement Officer shall then add the Price score to the committee s technical evaluation score for each proposal to produce the final score and rank order of the Offerors. Award shall then be made pursuant to the Basis of Award Source Selection section included herein. 10 P age

13 Required Criteria Table Weight Contractor Qualifications 15 A. Evaluation will be based on the relevant experience, references, and qualifications of the proposed personnel and subcontractors. B. As part of this RFP, the Contractor shall provide information as requested in the following tables, located in attachments ( The contractor shall provide requested information as accurately as possible, and respond with complete and explicit answers to the questions presented. The Contractor shall not provide tables and generic product information. When possible, the Contractor shall use the tables provided to answer the questions, or to make references to documents being submitted: SCADA: Table Business Requirements. Table Quality Control and Team members Table Proposed Team Members Table Ability to Deliver Coordination Study Proposal: Table Business Requirements. Table Quality Control and Team members Table Proposed Team Members Table Ability to Deliver C. An offeror must demonstrate a significant history of successfully completed Electrical SCADA software and Hardware projects, fault coordination studies, relay setting, relay testing, and arc flash studies. Experience related to previous projects of similar size, scope, and complexity will be evaluated to assess Offeror s qualifications to manage and perform the requirements of this solicitation. Past performance (on similar projects) will be evaluated to determine the quality of work previously provided and to assess the capability of the Offeror to effectively accomplish the requirements of this solicitation. UAF may obtain information from references provided by the Offeror, customers known to UAF, consumer protection organizations, and any other source that may have useful and relevant information. If discussions are held, an Offeror will be provided the opportunity to comment on past performance information obtained. In the attachment: Contractor Project Summary Form, located in Volume 1 Attachments, provide specific details of the Contractor s experience with electrical SCADA controls system, or other highlighted projects, in the last five years. Do not include projects that were completed before the year Provide a list of references with names of individuals involved and their specific responsibilities. Offerors are advised to inform references that UAF may contact them regarding their performance under previous contracts. 11 P age

14 Offeror s are required to provide the following: A minimum of 3 contracts and subcontracts (similar in size, scope, and complexity) completed during the last five (5) years, or currently in process. Contracts listed may include those entered into with federal, state, university, or local agencies, as well as contracts with commercial entities. Include the following information for each contract/subcontract. Management: 1. Reference Name: Project Name 2. Location: City, County, State, and Country 3. Date: Year project commissioned 4. Contact Name: First and Last Name 5. Title: Title of the Contact 6. Phone: Contact phone number 7. Contact address 8. Industry: Type of industry (Educational Institutions, Hospitals/Healthcare, Electrical Utility, substation, wastewater, water, power, etc.), project size and capacity for the industry (KW/ MW, etc.), and Contracting Officer name with phone number and address Attachments link: IED (Intelligent Electronic Devices): 1. IED Make: Make and version of IED 2. IED Model: Model of IED hardware and Brand name 3. IED: Quantity of each IED The Offeror shall provide information detailing any problems on the contracts and subcontracts identified and any corrective action taken. Provide a brief description of pending disputes or claims. Be specific in identifying problems and describing resolutions. This information is required as UAF may award without discussions or negotiations. Failure to provide a conclusive list of all past performance and experience within the past three (3) years will result in a lower technical evaluation score and may result in an offer being declared non-responsive and removed from further consideration. The offeror may submit evidence that verifies receipt of any awards, commendations, or certifications which reflect the quality of workmanship and service provided. 12 P age

15 Required Criteria Table Weight Methodology, Efficiency, Comprehension, and Schedule Provide Technical Response 45 Evaluation will be based on clarity and completeness of proposal, adherence to specification, demonstration of understanding project function and goals, evidence of schedule comprehension and ability to meet milestones and deadlines, demonstrate expertise to engineer and manage a multifaceted project to coordinated conclusion, resulting in best proposed design solution. The Contractor shall read the RFP in its entirety to gain an understanding of the overall concepts. The RFP requirements are described in detail for a thorough, measurable, and fair evaluation. Evaluation will be based upon the required submittals as specified throughout the solicitation. The required submittals as referenced in the checklist of required submittals as well as methodology narratives and proposed project solutions make up the criteria for technical evaluation of this section. Attachments Link: Required Criteria Table Weight Cost (Rate Response Form) 40 TOTAL OF ALL WEIGHTS P age

16 RATE RESPONSE FORM (2 PAGES) Offerors must complete this Rate Response Form and submit it, as a separate Adobe PDF and native file. Complete all forms and submit with your proposal in the order indicated on the Electronic Signature Page as a single Adobe PDF file. Do not include rate information in the technical offer or any other part of your proposal. Offers will consist of two PDF files. Note: Faxed or telegraphed proposals are not acceptable and shall be rejected as non-responsive. OFFERS WILL BE RECEIVED IN THE FOLLOWING FORMAT(S): USB Flash Memory CD or DVD RATE RESPONSE FORM UAF ELECTRICAL SCADA SYSTEM SERVICES, NON-PERSONAL: Electrical Supervisory Control and Data Acquisition System (SCADA) as specified herein, to include engineering, design, field support services, hardware, software, materials, supplies, labor, programming, installation, configuration, training, testing, commissioning, and acceptance. Additional project components as specified herein and included: Electric power system Arc Flash, short circuit, fault analysis, and coordination study. **************************************************** For informational purposes, please provide the following cost and/or price information for additional services as requested: Parts (Procured) Cost Plus Markup Percentage Parts (Manufactured) Discount Off List Price Percentage.. (list below your different labor categories/types and hourly rate for each) *LABOR TYPE: Total Price $ ************************* % % Hourly Hourly Hourly Hourly Hourly Hourly 14 P age

17 LABOR TYPE: Hourly Hourly * The rates offered are for additional services as requested, and are the fixed rates the University will be charged for all parts and labor which are not included in the scope of work, but approved by the Contract Administrator. The Contractor shall provide invoices for all parts supplied providing the proper documentation to support price. These rates shall not be part of the price evaluation but shall be compared with other offerors rates to ensure that they are reasonable. If the rates are found to be unreasonable, the University may remove the offeror from further consideration. Vendor Name: Company:. 15 P age

18 SCOPE OF WORK AND SPECIFICATION (SUMMARIZED) SUMMARY: The Contractor shall provide all engineering, design, management, supervision, personnel, labor, programming, installation, support services, hardware, software, materials, supplies, equipment, training, testing, and commissioning associated with an electrical SCADA system services and other services as specified. SUMMARIZED SCOPE OF SERVICES AND SPECIFICATIONS ( The work includes, but is not limited to, electrical and control work specified and shown on the Drawings for providing an Electrical SCADA system. 1. Complete the Electrical SCADA design for the electric power system consisting of the following major components for 65%, 95% and Issue for Construction (IFC) package. This package be used by UAF to install cabinets, equipment and wiring provided by the contractor. a. SCADA for monitoring and control of the Campus Switchgear Building (CSB) consisting of 12.4KV Switchgear A & B Lineup. Refer to Drawing No. HGI b. SCADA for monitoring and control of the Atkinson Steam Plant Building (SP) consisting of Tie Switchgear, Plant Switchgear and Master SCADA control cabinet. Refer to Drawing No. HGI c. SCADA for monitoring and control of the Diesel Generator Building (DG) consisting of the switchgear. Refer to Drawing No. HGI d. SCADA for monitoring and control of the GVEA Substation (GVEA) consisting of the Tie Shack and Utility Tie Enclosure. Refer to Drawing No. HGI and 06. e. Fiber Optics network to support the SCADA and electrical switchgear infrastructure consisting of fiber optical patch panels in each building, up to 36 fiber strands of Multimode and single mode, complete bill of material and all accessories required. f. Perform a complete electrical design including cabling, cable pathways and branch circuit breakers within existing panel boards. g. Perform and provide a written report for the Electrical System model and fault coordination study that will be used for the Protection Relay Settings Campus wide. h. UAF intends to incorporate load shedding in the future. Provide a narrative that demonstrates the capability of the supplied system to be expanded/modified in the future. The narrative should include the following components: Load Shedding, Islanding detection and intelligent system separation, Generation and frequency control, Voltage 16 P age

19 and MVAR control, Monitoring, Diagnostics, and Reporting, and Load management schemes. 2. Based on the design, provide the electric power system Electrical SCADA system. a. Within the Campus Switchgear Building (CSB). b. Within the Atkinson Steam Plant Building (SP). c. Within the Diesel Plant (DP). d. Within the GVEA Substation (GVEA). e. Programming and configuration of the SCADA System based on the developed SCADA monitoring and control narrative. f. Site Acceptance Testing of the SCADA System. g. Construction support for the installation of the SCADA System including Fiber Optics Infrastructure. h. Perform Protection Relay Settings for the CSB, DP, GVEA, and SP. Test Relays as required by the specification. i. Perform and document detailed electrical equipment acceptance testing of the SCADA System. j. Commissioning of the SCADA System including Site Acceptance Testing. k. Training. l. Turnover Package and Documentation consisting of; As-Built, Warranty Certificates, Installation, Operations and Maintenance Manuals, Software User Manuals, Program setting sheets with parameter values and description and Preventative Maintenance Standard Operating Procedures (SOP). These shall be provided in bound hard copy and digitally. Parameter settings shall be in native format. 3. Provide Contract Documentation per attachments and as otherwise specified. a. Accomplishment of work in the Contract Documents shall meet all requirements and dates specified in attachments. b. The above description is not intended to be complete. The work to be completed is provided in the contract specification documents. The listing in this section is not intended to relieve the Contractor of the responsibility for reading and understanding the contract specification documents. 17 P age

20 c. Federal, State and Local Laws, Statutes and Regulations are not individually referenced. This provision incorporates by reference the latest version of statutes, laws and regulations. SVC is responsible to comply with all applicable laws and regulation. Attachments Link: CHECK LIST OF REQUIRED SUBMITTALS To be considered for award, proposals must include all required submittals. To assist Offerors in returning all of the required information, the following checklist has been prepared. Proposals failing to comply with the requirements examined during the Administrative Evaluation may be declared nonresponsive and may be eliminated from further consideration. In accordance with the Instructions to Offerors and Proposal Evaluation section herein, and as part of the determination of the Offeror s technical qualifications, the following information must be submitted with your proposal: Proposal Transmittal Form (Electronic Signature Page Link) Statement of Compliance Form (Electronic Signature Page Link) Representations, Certifications, and Statements of Offerors (Electronic Signature Page Link) Proof of a current Alaska Business License Certificate of Insurance or letter of intent to insure Demonstration of ability to provide payment & performance bonding Submittal Requirements for Contractors Qualification and Technical Evaluation: Attachment and Table Links: Cover Letter RFP Response Table of Contents Brief Overview of the SCADA Vendor/Contractor Brief Overview of the Subcontractors or consultants Proposed Team Description Written Description of SCADA Project Understanding Written Description of Technical Approach List of Figures and Tables Proposed system drawings Completed Contractor Question Section (Tables ) in.pdf format 18 P age

21 Completed Contractor Question Section (Tables ) Complete Past (recent) Project References (Table 3.4) in.pdf format Complete Past (recent) Project References (Table 3.4) Complete BOM excluding cost column (Tables and ) Complete Business Requirements (Tables 5.3.x 5.4) Products and Submittals Campus Substation Building (Use table 4.1) Atkinson Steam Plant (Use table 4.2) GVEA Utility tie shack and tie enclosure (Use table 4.3) Diesel Plant (Use table 4.4) Attachment, Specification and Table Links: The Contractor shall provide the requested information as accurately as possible, and respond with complete and explicit answers to the questions presented herein. The Contractor shall not provide generic tables and generic product information. The Contractor shall use the Summary of Material tables 4.1 through 4.4 that are provided with this RFP as an example of what to provide in their response in pdf format. A. The Contractor shall submit a technical proposal to demonstrate a thorough understanding of the requirements of this RFP. The technical proposal shall describe a logical plan for accomplishing the technical requirements for the UAF SCADA project and integrating the various campus buildings. The technical description shall include, where applicable, sketches, drawings, written descriptions of techniques, and a complete explanation of the proposed procedures. B. The Contractor is encouraged to include optional equipment or services that may be of value in determining the following: 1. Equipment configurations 2. Optional functionality 3. Software packages, etc. Any optional equipment listed will have its significant features clearly identified, including a brief statement as to how UAF would benefit from the optional item, if selected. C. Commercial elements of the Contractor s solution shall be listed. All equipment, options, and services mentioned will have a corresponding commercial entry listed. All of the sections of this RFP are intended to build an understanding of the overall intent and depth of the project, and completed as clearly and accurately as possible. Elaborate format, binding, and marketing presentations are not necessary or desired. Legibility, clarity, and completeness of the technical approach are more important and strongly suggested as the most appropriate approach. 19 P age

City of Hays Request for Proposal. Wastewater Treatment Plant Fiber Connectivity

City of Hays Request for Proposal. Wastewater Treatment Plant Fiber Connectivity City of Hays Request for Proposal Wastewater Treatment Plant Fiber Connectivity Date of Issue: 3-15-2016 Proposal Due Date: 4-12-2016 CITY OF HAYS, KANSAS CITY CONTRACTS This contract is subject to the

More information

Request for Proposal: Alton Middle School NETWORK CABLING

Request for Proposal: Alton Middle School NETWORK CABLING Alton Community Unit School District #11 -Technology Department - Request for Proposal: Alton Middle School NETWORK CABLING Low Voltage Network Cabling Installation (ERATE Category II) Bid Reference: NET_AMS-WIRING_1617

More information

SOLICITATION FOR PARTICIPATION IN A REQUEST FOR PROPOSALS FOR CHIEF EXECUTIVE OFFICER (CEO) SEARCH SERVICES JACKSONVILLE, FL SOLICITATION NUMBER 94414

SOLICITATION FOR PARTICIPATION IN A REQUEST FOR PROPOSALS FOR CHIEF EXECUTIVE OFFICER (CEO) SEARCH SERVICES JACKSONVILLE, FL SOLICITATION NUMBER 94414 SOLICITATION FOR PARTICIPATION IN A REQUEST FOR PROPOSALS FOR CHIEF EXECUTIVE OFFICER (CEO) SEARCH SERVICES JACKSONVILLE, FL SOLICITATION NUMBER 94414 PROPOSALS ARE DUE ON APRIL 27, 2018 BY 12:00 PM EST

More information

Lyndon Township Broadband Implementation Committee Lyndon Township, Michigan

Lyndon Township Broadband Implementation Committee Lyndon Township, Michigan Lyndon Township Broadband Implementation Committee Lyndon Township, Michigan Request for Proposal For Consulting Services For a Fiber-to-the-Home Network In Lyndon Township Proposals may be mailed or delivered

More information

REQUEST FOR PROPOSALS. For: As needed Plan Check and Building Inspection Services

REQUEST FOR PROPOSALS. For: As needed Plan Check and Building Inspection Services Date: June 15, 2017 REQUEST FOR PROPOSALS For: As needed Plan Check and Building Inspection Services Submit Responses to: Building and Planning Department 1600 Floribunda Avenue Hillsborough, California

More information

ISABELLA COUNTY REQUEST FOR PROPOSALS COMMISSION ON AGING CATV AND HEADEND EQUIPMENT

ISABELLA COUNTY REQUEST FOR PROPOSALS COMMISSION ON AGING CATV AND HEADEND EQUIPMENT ISABELLA COUNTY REQUEST FOR PROPOSALS COMMISSION ON AGING CATV AND HEADEND EQUIPMENT ISSUED BY ISABELLA COUNTY BOARD OF COMMISSIONERS ISSUE DATE: February 4, 2008 ISABELLA COUNTY REQUEST FOR PROPOSALS

More information

WESTMINSTER SCHOOL DISTRICT NUTRITION SERVICES REQUEST FOR PROPOSAL FRESH PRODUCE 17/ For: July 1, 2018 to June 30, 2019

WESTMINSTER SCHOOL DISTRICT NUTRITION SERVICES REQUEST FOR PROPOSAL FRESH PRODUCE 17/ For: July 1, 2018 to June 30, 2019 WESTMINSTER SCHOOL DISTRICT NUTRITION SERVICES REQUEST FOR PROPOSAL FRESH PRODUCE 17/18-05 For: July 1, 2018 to June 30, 2019 DUE DATE OF PROPOSAL: MONDAY, APRIL 23, 2018-8:00 AM DROPPING OFF PROPOSAL:

More information

REQUEST FOR PROPOSAL: SAN EXPANSION & OPTIMIZATION

REQUEST FOR PROPOSAL: SAN EXPANSION & OPTIMIZATION REQUEST FOR PROPOSAL: SAN EXPANSION & OPTIMIZATION Issued: November 21, 2014 TABLE OF CONTENTS 1. Introduction...3 1.1 Purpose...3 1.2 Background...3 1.3 Summary of Services Required...3 2. Key Information

More information

Social Media Management System

Social Media Management System REQUEST FOR PROPOSAL No. DC177387P Social Media Management System PROPOSAL DUE DATE AND TIME August 25, 2015 (2:00 AM, PT) SUBMITTAL LOCATION Oregon State University Procurement, Contracts and Materials

More information

INVITATION FOR BID Notice to Prospective Bidders IFB # Date Stamp Equipment Preventative Maintenance and Repair Services

INVITATION FOR BID Notice to Prospective Bidders IFB # Date Stamp Equipment Preventative Maintenance and Repair Services INVITATION FOR BID Notice to Prospective Bidders Date Stamp Equipment Preventative Maintenance and Repair Services June 1, 2011 You are invited to review and respond to this Invitation for Bid (IFB), entitled

More information

REQUEST FOR PROPOSAL After Hours Answering Services

REQUEST FOR PROPOSAL After Hours Answering Services REQUEST FOR PROPOSAL 2018-027-1300005 After Hours Answering Services INSTRUCTIONS TO OFFERORS This is a Loudoun Water Request for Proposal to establish a contract through competitive negotiations for the

More information

TEXAS DEPARTMENT OF TRANSPORTATION INSPECT, SAMPLE, AND TEST FOR ASBESTOS CONTAINING MATERIAL AND MONITOR ABATEMENT PROJECTS PUBLICATION

TEXAS DEPARTMENT OF TRANSPORTATION INSPECT, SAMPLE, AND TEST FOR ASBESTOS CONTAINING MATERIAL AND MONITOR ABATEMENT PROJECTS PUBLICATION * TEXAS DEPARTMENT OF TRANSPORTATION INSPECT, SAMPLE, AND TEST FOR ASBESTOS CONTAINING MATERIAL AND MONITOR ABATEMENT PROJECTS PUBLICATION This specification is a product of the Texas Department of Transportation

More information

Automated License Plate Reader (ALPR) System. City of Coquitlam. Request for Proposals RFP No Issue Date: January 25, 2017

Automated License Plate Reader (ALPR) System. City of Coquitlam. Request for Proposals RFP No Issue Date: January 25, 2017 Request for Proposals RFP No. 17-01-06 Automated License Plate Reader (ALPR) System Issue Date: January 25, 2017 File #: 03-1220-20/17-01-06/1 Doc #: 2519682.v1 RFP No. 17-01-06 Automated License Plate

More information

City of Gainesville State of Georgia

City of Gainesville State of Georgia City of Gainesville State of Georgia Request for Proposals RFP No. 18037 Downtown Public Wireless Network Project Proposal Release: May 24, 2018 Pre-Proposal Meeting: June 8, 2018 at 2:30 p.m. EST Proposal

More information

TOPIC: CONTRACTS STATE OF MISSISSIPPI DEPARTMENT OF EDUCATION SECTION 17.0 PAGE 1 OF 38 EFFECTIVE DATE: MAY 1, 2017 REVISION #4: MARCH 1, 2017

TOPIC: CONTRACTS STATE OF MISSISSIPPI DEPARTMENT OF EDUCATION SECTION 17.0 PAGE 1 OF 38 EFFECTIVE DATE: MAY 1, 2017 REVISION #4: MARCH 1, 2017 SECTION 17.0 PAGE 1 OF 38 CONTRACT PROCUREMENT POLICY The Mississippi Department of Education (Department) Contract Procurement Policy set forth herein applies to the procurement, management, and control

More information

Request for Proposals School Year Project Lafayette County School District 100 Commodore Drive Oxford, MS 38655

Request for Proposals School Year Project Lafayette County School District 100 Commodore Drive Oxford, MS 38655 Request for Proposals 2018 2019 School Year Project Lafayette County School District 100 Commodore Drive Oxford, MS 38655 Notice to Bidders Notice is hereby given to interested bidders that the Lafayette

More information

Request for Proposals VoIP E-Rate Project Perry County School District. 105 Main Street. New Augusta, MS

Request for Proposals VoIP E-Rate Project Perry County School District. 105 Main Street. New Augusta, MS Request for Proposals 2013 2014 VoIP E-Rate Project Perry County School District 105 Main Street New Augusta, MS 39462 January 31, 2013 Notice to Bidders Notice is hereby given to interested bidders that

More information

Proposals due May 18 th, 2018 at 4:30 PM. Indicate on the Sealed Envelope Do Not Open with Regular Mail.

Proposals due May 18 th, 2018 at 4:30 PM. Indicate on the Sealed Envelope Do Not Open with Regular Mail. April 26, 2018 Subject: RFP2M18-06: Request for Proposal Construction Management and Inspection Services for the Sewer Plant #7 Replacement Project. The City of Alhambra is requesting proposals from experienced,

More information

INVITATION TO NEOGOTIATE ISSUED DATE ITN #

INVITATION TO NEOGOTIATE ISSUED DATE ITN # INVITATION TO NEOGOTIATE ISSUED DATE ITN # 14-0001 I. Introduction The Florida Alliance for Assistive Services and Technology, Inc. hereafter referred to as FAAST, is requesting sealed proposals from qualified

More information

201 North Forest Avenue Independence, Missouri (816) [September 25, 2017] REQUEST FOR PROPOSAL GRADUATION CAPS AND GOWNS

201 North Forest Avenue Independence, Missouri (816) [September 25, 2017] REQUEST FOR PROPOSAL GRADUATION CAPS AND GOWNS 201 North Forest Avenue Independence, Missouri 64050 (816) 521-5300 [September 25, 2017] REQUEST FOR PROPOSAL GRADUATION CAPS AND GOWNS Sealed proposals will be received by the Independence School District

More information

REQUEST FOR PROPOSALS RFP# CAFTB

REQUEST FOR PROPOSALS RFP# CAFTB REQUEST FOR PROPOSALS RFP# CAFTB25092017-01 THE CHILDREN S AID FOUNDATION OF THE DISTRICT OF THUNDER BAY WEBSITE REDESIGN/DEVELOPMENT Issue Date: 25 September 2017 Closing Date: 20 October 2017 Submit

More information

Request for Proposals City School District of Albany Empire State After-School Program Coordination and Programming June 14, 2017

Request for Proposals City School District of Albany Empire State After-School Program Coordination and Programming June 14, 2017 Request for Proposals City School District of Albany Empire State After-School Program Coordination and Programming June 14, 2017 Attention: Purchasing Agent Address: City School District of Albany 1 Academy

More information

REQUEST FOR PROPOSAL FOR SECURITY CAMERA INSTALLATION: Stones River Baptist Church. 361 Sam Ridley Parkway East. Smyrna, Tennessee 37167

REQUEST FOR PROPOSAL FOR SECURITY CAMERA INSTALLATION: Stones River Baptist Church. 361 Sam Ridley Parkway East. Smyrna, Tennessee 37167 REQUEST FOR PROPOSAL FOR SECURITY CAMERA INSTALLATION: Stones River Baptist Church 361 Sam Ridley Parkway East Smyrna, Tennessee 37167 Released on February 2, 2018 SECURITY CAMERA INSTALLATION Stones River

More information

Request for Proposals

Request for Proposals Request for Proposals Disparity Study PROPOSALS WILL BE RECEIVED UNTIL 12:00 Noon, Friday, July 27 th, 2018 in Purchasing Department, City Hall Building 101 North Main Street, Suite 324 Winston-Salem,

More information

All proposals must be received by August 30, 2016 at 2:00 PM EST

All proposals must be received by August 30, 2016 at 2:00 PM EST July 25, 2016 REQUEST FOR PROPOSAL Northwood School District SAU #44 Strategic Planning for the Northwood School District You are cordially invited to submit a proposal for Strategic Planning for the Northwood

More information

REQUEST FOR PROPOSALS FOR REPLACEMENT OF GENERATOR AT LAKE HILLS 1860 BOOSTER PUMP STATION

REQUEST FOR PROPOSALS FOR REPLACEMENT OF GENERATOR AT LAKE HILLS 1860 BOOSTER PUMP STATION REQUEST FOR PROPOSALS FOR REPLACEMENT OF GENERATOR AT LAKE HILLS 1860 BOOSTER PUMP STATION Issue Date: October 18th, 2016 Submission Deadline: November 8th, 2016, 2:00 PM P a g e 1 Table of Contents Introduction...

More information

CITY AND COUNTY OF SAN FRANCISCO DEPARTMENT OF ELECTIONS

CITY AND COUNTY OF SAN FRANCISCO DEPARTMENT OF ELECTIONS CITY AND COUNTY OF SAN FRANCISCO DEPARTMENT OF ELECTIONS ADDENDUM #1 ISSUSED ON May 13, 2005 REQUEST FOR PROPOSALS FOR A NEW VOTING SYSTEM RFP#NVS0305 1) Please add and substitute the following Addendum

More information

Massachusetts Bay Transportation Authority. POLICIES & PROCEDURES Design Build Procurement Procedures April 2016

Massachusetts Bay Transportation Authority. POLICIES & PROCEDURES Design Build Procurement Procedures April 2016 Massachusetts Bay Transportation Authority POLICIES & PROCEDURES Design Build Procurement Procedures April 2016 Design Build Procurement Procedures April 2016 Massachusetts Bay Transportation Authority

More information

Georgia Lottery Corporation ("GLC") PROPOSAL. PROPOSAL SIGNATURE AND CERTIFICATION (Authorized representative must sign and return with proposal)

Georgia Lottery Corporation (GLC) PROPOSAL. PROPOSAL SIGNATURE AND CERTIFICATION (Authorized representative must sign and return with proposal) NOTE: PLEASE ENSURE THAT ALL REQUIRED SIGNATURE BLOCKS ARE COMPLETED. FAILURE TO SIGN THIS FORM AND INCLUDE IT WITH YOUR PROPOSAL WILL CAUSE REJECTION OF YOUR PROPOSAL. Georgia Lottery Corporation ("GLC")

More information

1 INTERNAL AUDIT SERVICES RFP

1 INTERNAL AUDIT SERVICES RFP 1 Price Proposal... 4 Introduction... 7 Scope of Work... 7 Expected Outcomes and Deliverables... 8 Selection Process... 8 Qualification and Evaluation of Proposals... 9 Proposer Representations... 10 Basis

More information

REQUEST FOR PROPOSAL (RFP) # CONSULTANT SERVICES FOR DEVELOPMENT OF A DISTRICT SUSTAINABILITY PLAN

REQUEST FOR PROPOSAL (RFP) # CONSULTANT SERVICES FOR DEVELOPMENT OF A DISTRICT SUSTAINABILITY PLAN REQUEST FOR PROPOSAL (RFP) #1314-15 CONSULTANT SERVICES FOR DEVELOPMENT OF A DISTRICT SUSTAINABILITY PLAN Request for Proposal must be received no later than January 3, 2014 at 2:00 pm CARRI MATSUMOTO

More information

Request for Proposal (RFP)

Request for Proposal (RFP) Consolidated Edison Company of New York, Inc. Request for Proposal (RFP) Non-Wires Alternatives to Provide Demand Side Management for Transmission and Distribution System Load Relief Columbus Circle Network

More information

Ontario College of Trades

Ontario College of Trades Ontario College of Trades This document is a Request fo r Proposal (RFP) for Roster of vendors to facilitate: Ontario College of Trades 2018 Strategic Planning Initiative (planning, facilitating and reporting

More information

TERREBONNE PARISH REQUEST FOR QUALIFICATIONS FOR ENGINEERING SERVICES. Generator Sizing and Installation

TERREBONNE PARISH REQUEST FOR QUALIFICATIONS FOR ENGINEERING SERVICES. Generator Sizing and Installation TERREBONNE PARISH REQUEST FOR QUALIFICATIONS FOR ENGINEERING SERVICES Generator Sizing and Installation Proposal Due Date: June 26, 2017 Proposal Due Time: 2:00 P.M. Released May 23, 2017 Table of Contents

More information

REQUEST FOR PROPOSAL FOR Web Hosting. Anniston City Schools. FRP Number FY2012 Web Hosting

REQUEST FOR PROPOSAL FOR Web Hosting. Anniston City Schools. FRP Number FY2012 Web Hosting REQUEST FOR PROPOSAL FOR Web Hosting Anniston City Schools FRP Number FY2012 Web Hosting Anniston City School District 4804 McClellan Blvd Anniston, Al 36206 www.annistonschools.com Objective The Anniston

More information

Request for Proposal

Request for Proposal Consolidated Edison Company of New York, Inc. Request for Proposal Non-Wires Solutions to Provide Demand Side Management for Subtransmission and Distribution System Load Relief Newtown Substation Project

More information

SUPERIOR COURT OF CALIFORNIA, SANTA BARBARA COUNTY REGARDING:

SUPERIOR COURT OF CALIFORNIA, SANTA BARBARA COUNTY REGARDING: REQUEST FOR QUOTES SUPERIOR COURT OF CALIFORNIA, SANTA BARBARA COUNTY REGARDING: ONLINE INFORMATION TECHNOLOGY TRAINING PROVIDER RFP 2017-010 QUOTES DUE: Wednesday, October 25 NO LATER THAN 3:00 P.M. PACIFIC

More information

Request for Proposal

Request for Proposal Consolidated Edison Company of New York, Inc. Request for Proposal Non-Wires Solutions to Provide Demand Side Management for Subtransmission and Distribution System Load Relief West 42 nd Street Load Transfer

More information

Request for Proposals (RFP) to Provide Auditing Services

Request for Proposals (RFP) to Provide Auditing Services March 2016 Request for Proposals (RFP) to Provide Auditing Services Proposals due no later than 5:00 p.m. on April 7, 2016 Monte Vista Water District 10575 Central Avenue Montclair, California 91763 1

More information

REQUEST FOR PROPOSAL AUDITING SERVICES. Chicago Infrastructure Trust

REQUEST FOR PROPOSAL AUDITING SERVICES. Chicago Infrastructure Trust REQUEST FOR PROPOSAL AUDITING SERVICES Chicago Infrastructure Trust 10 August 2016 Table of Contents Background Information... 3 Objective and Scope of Services... 3 RFP Process and Submission Requirements...

More information

SEALED PROPOSAL REQUEST FOR PROPOSAL. Professional Archaelogical Services

SEALED PROPOSAL REQUEST FOR PROPOSAL. Professional Archaelogical Services Department of Forests, Parks & Recreation 1 National Life Drive, Davis 2 Montpelier, VT 05620-3801 www.vtfpr.org Agency of Natural Resources SEALED PROPOSAL REQUEST FOR PROPOSAL Professional Archaelogical

More information

Request for Proposal George West Independent School District ERate

Request for Proposal George West Independent School District ERate Request for Proposal ERate 2015-2016 Local Phone Service, Long Distance Phone Service, Digital Transmission Service, Internet Access Due: February 25, 2015, 2:00 PM Superintendent: Ty Sparks ERate 2015

More information

SOLICITATION NO: 15-1 REQUEST FOR PROPOSALS (RFP) FOR ARCHITECTURAL SERVICES FOR NEW ELEMENTARY SCHOOL #3

SOLICITATION NO: 15-1 REQUEST FOR PROPOSALS (RFP) FOR ARCHITECTURAL SERVICES FOR NEW ELEMENTARY SCHOOL #3 SOLICITATION NO: 15-1 REQUEST FOR PROPOSALS (RFP) FOR ARCHITECTURAL SERVICES FOR NEW ELEMENTARY SCHOOL #3 BIBB COUNTY SCHOOL DISTRICT 484 Mulberry Street Macon, Georgia 31201 July 18, 2014 TIMELINE RFP

More information

Request for Proposal

Request for Proposal Request for Proposal ************** Acquisition of [16] Zoll AEV 731 Ventilators Texas Emergency Medical Task Force State Coordinating Office 6 April 2018 Southwest Texas Regional Advisory Council 7500

More information

Midway City Council 11 July 2018 Regular Meeting. Financial Advisory Services / Award Contract

Midway City Council 11 July 2018 Regular Meeting. Financial Advisory Services / Award Contract Midway City Council 11 July 2018 Regular Meeting Financial Advisory Services / Award Contract REQUEST FOR PROPOSALS FINANCIAL ADVISORY SERVICES NOTICE IS HEREBY GIVEN, that Midway City is requesting proposals

More information

STATE OF MAINE Department of Economic and Community Development Office of Community Development

STATE OF MAINE Department of Economic and Community Development Office of Community Development STATE OF MAINE Department of Economic and Community Development Office of Community Development RFP#201711194 Efficient Delivery of Local and Regional Services RFP Coordinator Submitted Questions Due Proposal

More information

STATE OF FLORIDA DEPARTMENT OF CHILDREN AND FAMILIES OFFICE OF CHILD WELFARE

STATE OF FLORIDA DEPARTMENT OF CHILDREN AND FAMILIES OFFICE OF CHILD WELFARE STATE OF FLORIDA DEPARTMENT OF CHILDREN AND FAMILIES OFFICE OF CHILD WELFARE REQUEST FOR PROPOSALS ADOPTION AND INDEPENDENT LIVING SERVICES RFP# 07J15GN1 Commodity Code #: 93141505 1 TABLE OF CONTENTS

More information

LEXINGTON-FAYETTE URBAN COUNTY AIRPORT BOARD REQUEST FOR PROPOSALS. to provide INVESTMENT MANAGEMENT SERVICES. for BLUE GRASS AIRPORT

LEXINGTON-FAYETTE URBAN COUNTY AIRPORT BOARD REQUEST FOR PROPOSALS. to provide INVESTMENT MANAGEMENT SERVICES. for BLUE GRASS AIRPORT LEXINGTON-FAYETTE URBAN COUNTY AIRPORT BOARD REQUEST FOR PROPOSALS to provide INVESTMENT MANAGEMENT SERVICES for BLUE GRASS AIRPORT DATED: March 5, 2017 TABLE OF CONTENTS 1. NOTICE AND REQUEST FOR PROPOSALS...

More information

REQUEST FOR PROPOSAL FOR POLICE OPERATIONS STUDY. Police Department CITY OF LA PALMA

REQUEST FOR PROPOSAL FOR POLICE OPERATIONS STUDY. Police Department CITY OF LA PALMA REQUEST FOR PROPOSAL FOR POLICE OPERATIONS STUDY Police Department CITY OF LA PALMA Released on November 27, 2013 Police Operations Study REQUEST FOR PROPOSAL ( RFP ) 1. BACKGROUND The City of La Palma

More information

PROGRAM OPPORTUNITY NOTICE EFFICIENCY MAINE TRUST CUSTOM INCENTIVE PROGRAM FOR DISTRIBUTED GENERATION PROJECTS PON EM

PROGRAM OPPORTUNITY NOTICE EFFICIENCY MAINE TRUST CUSTOM INCENTIVE PROGRAM FOR DISTRIBUTED GENERATION PROJECTS PON EM PROGRAM OPPORTUNITY NOTICE EFFICIENCY MAINE TRUST CUSTOM INCENTIVE PROGRAM FOR DISTRIBUTED GENERATION PROJECTS PON Opening: July 1, 2017 Closing: June 30, 2018 Updated: July 1, 2017 CONTENTS SECTION 1:

More information

BID # Hunters Point Community Library. Date: December 20, Invitation for Bid: Furniture & Shelving

BID # Hunters Point Community Library. Date: December 20, Invitation for Bid: Furniture & Shelving BID # 1217-2 Hunters Point Community Library Date: December 20, 2017 Invitation for Bid: Furniture & Shelving Bids must be submitted by: January 17, 2018 2:00 P.M., to: Purchasing Department Queens Borough

More information

TEXAS GENERAL LAND OFFICE COMMUNITY DEVELOPMENT & REVITALIZATION PROCUREMENT GUIDANCE FOR SUBRECIPIENTS UNDER 2 CFR PART 200 (UNIFORM RULES)

TEXAS GENERAL LAND OFFICE COMMUNITY DEVELOPMENT & REVITALIZATION PROCUREMENT GUIDANCE FOR SUBRECIPIENTS UNDER 2 CFR PART 200 (UNIFORM RULES) TEXAS GENERAL LAND OFFICE COMMUNITY DEVELOPMENT & REVITALIZATION PROCUREMENT GUIDANCE FOR SUBRECIPIENTS UNDER 2 CFR PART 200 (UNIFORM RULES) The Texas General Land Office Community Development & Revitalization

More information

ADDENDUM NUMBER 02 TO THE BID DOCUMENTS. BID NUMBER: SJCC Parking Garage LED Lighting Retrofit EVERGREEN VALLEY COLLEGE

ADDENDUM NUMBER 02 TO THE BID DOCUMENTS. BID NUMBER: SJCC Parking Garage LED Lighting Retrofit EVERGREEN VALLEY COLLEGE SAN JOSE EVERGREEN COMMUNITY COLLEGE DISTRICT ADDENDUM NUMBER 02 TO THE BID DOCUMENTS To all general contract bidders of record on the Bid Proposal: BID NUMBER:0215-17 SJCC Parking Garage LED Lighting

More information

REQUEST FOR QUALIFICATION FOR PREPARATION OF FACILITIES MASTER PLAN AND FUTURE ARCHITECTURAL SERVICES

REQUEST FOR QUALIFICATION FOR PREPARATION OF FACILITIES MASTER PLAN AND FUTURE ARCHITECTURAL SERVICES REQUEST FOR QUALIFICATION FOR PREPARATION OF FACILITIES MASTER PLAN AND FUTURE ARCHITECTURAL SERVICES September 22,2016 Mammoth Unified School District 461 Sierra Park Road/PO Box 3509, Mammoth Lakes,

More information

Regional Greenhouse Gas Initiative, Inc. Request for Proposals #18-01 RGGI Auction Services Contractor. June 18, 2018

Regional Greenhouse Gas Initiative, Inc. Request for Proposals #18-01 RGGI Auction Services Contractor. June 18, 2018 Regional Greenhouse Gas Initiative, Inc. Request for Proposals #18-01 RGGI Auction Services Contractor June 18, 2018 PROPOSAL DUE DATE: July 23, 2018, 5:00 p.m. Eastern Daylight Time The Regional Greenhouse

More information

Request for Proposals (RFP) for Police Body Worn Camera Systems and Video Storage Solutions For City of Boulder City, Nevada

Request for Proposals (RFP) for Police Body Worn Camera Systems and Video Storage Solutions For City of Boulder City, Nevada Request for Proposals (RFP) for Police Body Worn Camera Systems and Video Storage Solutions For City of Boulder City, Nevada Proposals Due: March 22, 2018 by 6:00 p.m. The City of Boulder City, Nevada

More information

REQUEST FOR PROPOSALS

REQUEST FOR PROPOSALS REQUEST FOR PROPOSALS First Missionary Baptist Church The Church that is striving to become one of the most loving churches in all the world. 3509 Blue Spring Road, Huntsville, Alabama 35810 256-852-4318,

More information

PUBLIC WORKS DEPARTMENT 22 E. Weber Avenue, Room 301 Stockton, CA (209) REQUEST FOR PROPOSALS PROFESSIONAL SERVICES FOR THE

PUBLIC WORKS DEPARTMENT 22 E. Weber Avenue, Room 301 Stockton, CA (209) REQUEST FOR PROPOSALS PROFESSIONAL SERVICES FOR THE PUBLIC WORKS DEPARTMENT 22 E. Weber Avenue, Room 301 Stockton, CA 95202-3717 (209) 937-8411 REQUEST FOR PROPOSALS PROFESSIONAL SERVICES FOR THE TRAFFIC SIGNAL, ROUNDABOUT, AND PROTECTED LEFT-TURN PHASING

More information

City of Malibu Request for Proposal

City of Malibu Request for Proposal Request for Proposal North Santa Monica Bay Coastal Watersheds Monitoring Services Date Issued: April 26, 2016 Date Due: May 17, 2016, 4:00 P.M. The Qualifications Proposal and Cost Proposal must be submitted

More information

Request for Proposal. Purchase of New Mobile Trailer Climbing Wall. No November 23, 2015

Request for Proposal. Purchase of New Mobile Trailer Climbing Wall. No November 23, 2015 Request for Proposal Purchase of New Mobile Trailer Climbing Wall No. 2016-002 November 23, 2015 1 Contents Price Proposal-----------------------------------------------------------------------------------------------------3

More information

REQUEST FOR PROPOSALS Thomas MacLaren State Charter School Classroom Furniture for K-5 School March 2, 2018

REQUEST FOR PROPOSALS Thomas MacLaren State Charter School Classroom Furniture for K-5 School March 2, 2018 REQUEST FOR PROPOSALS Thomas MacLaren State Charter School Classroom Furniture for K-5 School March 2, 2018 TO BE CONSIDERED, PROPOSALS MUST BE RECEIVED AT 1702 N MURRAY BLVD, COLORADO SPRINGS, CO 80915

More information

REQUEST FOR PROPOSALS FOR PENSION ADMINISTRATION AND FINANCIAL SYSTEMS CONSULTING SERVICES

REQUEST FOR PROPOSALS FOR PENSION ADMINISTRATION AND FINANCIAL SYSTEMS CONSULTING SERVICES REQUEST FOR PROPOSALS FOR PENSION ADMINISTRATION AND FINANCIAL SYSTEMS CONSULTING SERVICES Submission Deadline: 11:59 p.m. March 8, 2015 980 9 th Street Suite 1900 Sacramento, CA 95814 SacRetire@saccounty.net

More information

MISSISISSIPPI STATE UNIVERSITY Request for Proposals (RFP) MSU #18 03 Communications as a Service Solution

MISSISISSIPPI STATE UNIVERSITY Request for Proposals (RFP) MSU #18 03 Communications as a Service Solution MISSISISSIPPI STATE UNIVERSITY Request for Proposals (RFP) MSU #18 03 Communications as a Service Solution Issue Date: [12 5 17] Issuing Agency: Office of Procurement and Contracts Mississippi State University

More information

REQUEST FOR PROPOSALS FOR INFORMATION TECHNOLOGY SUPPORT SERVICES

REQUEST FOR PROPOSALS FOR INFORMATION TECHNOLOGY SUPPORT SERVICES REQUEST FOR PROPOSALS FOR INFORMATION TECHNOLOGY SUPPORT SERVICES ISSUE DATE: Bedford Township 8100 Jackman Rd. PO Box H Temperance, Michigan 48182 1 TABLE OF CONTENTS PAGE 1) Introduction 3 2) Sequence

More information

FLORIDA DEPARTMENT OF TRANSPORTATION

FLORIDA DEPARTMENT OF TRANSPORTATION FLORIDA DEPARTMENT OF TRANSPORTATION ADDENDUM NO.: 1 Date: May 12, 2015 To: All Proposers From: Procurement Office RE: Questions and Answers RFP-DOT-14/15-9030-GH-ReAd: EMERGENCY MANAGEMENT SERVICES Notice

More information

INVITATION TO BID (ITB) BID # FY

INVITATION TO BID (ITB) BID # FY INVITATION TO BID (ITB) BID # FY 2016-2017-005 SUPERVISORY CONTROL AND DATA ACQUISITION (SCADA) SOFTWARE SYSTEM INTEGRATION EXHIBIT I - SCOPE OF WORK PREPARED BY: CITY OF HALLANDALE BEACH DEPARTMENT OF

More information

SOUTH CAROLINA ELECTRIC & GAS COMPANY REQUEST FOR PROPOSALS FOR SOLAR PHOTOVOLTAIC DISTRIBUTED ENERGY RESOURCES AT TWO DESIGNATED SITES

SOUTH CAROLINA ELECTRIC & GAS COMPANY REQUEST FOR PROPOSALS FOR SOLAR PHOTOVOLTAIC DISTRIBUTED ENERGY RESOURCES AT TWO DESIGNATED SITES SOUTH CAROLINA ELECTRIC & GAS COMPANY REQUEST FOR PROPOSALS FOR SOLAR PHOTOVOLTAIC DISTRIBUTED ENERGY RESOURCES AT TWO DESIGNATED SITES AUGUST 21, 2014 Page 1 of 10 1. Overview SOUTH CAROLINA ELECTRIC

More information

REQUEST FOR PROPOSALS

REQUEST FOR PROPOSALS COMMUNITY REDEVELOPMENT AGENCY OF THE CITY OF SANTA ANA REQUEST FOR PROPOSALS RELOCATION OF TWO RESIDENTIAL STRUCTURES PROPOSALS DUE: Monday, May 9, 2011 at 11:00 AM 1. INTRODUCTION REQUEST FOR PROPOSALS

More information

NORTHWESTERN UNIVERSITY PROJECT NAME JOB # ISSUED: 03/29/2017

NORTHWESTERN UNIVERSITY PROJECT NAME JOB # ISSUED: 03/29/2017 SECTION 26 0800 - COMMISSIONING OF ELECTRICAL SYSTEMS PART 1 - GENERAL 1.1 SUMMARY A. The purpose of this section is to specify the Division 26 responsibilities and participation in the commissioning process.

More information

Request for Proposal: NETWORK FIREWALL

Request for Proposal: NETWORK FIREWALL Alton Community Unit School District #11 -Technology Department - Request for Proposal: NETWORK FIREWALL Equipment and Installation/Support (ERATE Category II) Bid Reference: NET_FIREWALL_1617 ISSUED:

More information

TOWN OF WINDERMERE REQUEST FOR PROPOSALS Race Timing & Event Services

TOWN OF WINDERMERE REQUEST FOR PROPOSALS Race Timing & Event Services TOWN OF WINDERMERE REQUEST FOR PROPOSALS Race Timing & Event Services RESPONSES ARE DUE BY 5:00 PM December 12, 2014 MAIL OR DELIVER RESPONSES TO: ATT: Robert Smith, Town Manager 614 Main St. Windermere,

More information

REQUEST FOR PROPOSALS (RFP) K430 INITIATIVE 502 CONSULTING SERVICES. To request this information in alternative formats call (360)

REQUEST FOR PROPOSALS (RFP) K430 INITIATIVE 502 CONSULTING SERVICES. To request this information in alternative formats call (360) State of Washington LIQUOR CONTROL BOARD 3000 Pacific Ave SE, P.O. Box 43090 Olympia, Washington 98504-3090 (360) 664-1700 http://www.liq.wa.gov/ REQUEST FOR PROPOSALS (RFP) K430 INITIATIVE 502 CONSULTING

More information

REQUEST FOR PROPOSALS FOR A HELP AMERICA VOTE ACT COMPLIANT VOTING SYSTEM ARSOS-HAVA--005

REQUEST FOR PROPOSALS FOR A HELP AMERICA VOTE ACT COMPLIANT VOTING SYSTEM ARSOS-HAVA--005 State of Arkansas Secretary of State A REQUEST FOR PROPOSALS FOR A HELP AMERICA VOTE ACT COMPLIANT VOTING SYSTEM ARSOS-HAVA--005 VR-RFP Ark. Draft No. 11 October 1, 2004 REQUEST FOR PROPOSALS (RFP) FOR

More information

Request for Proposals and Specifications for a Community Solar Project

Request for Proposals and Specifications for a Community Solar Project Request for Proposals and Specifications for a Community Solar Project CPS Energy P.O. Box 1771 San Antonio, TX 78296-1771 October 9, 2014 PR # 10452716 INVITATION TO SUBMIT PROPOSALS 1. Introduction CPS

More information

Request for Proposal for Digitizing Document Services and Document Management Solution RFP-DOCMANAGESOLUTION1

Request for Proposal for Digitizing Document Services and Document Management Solution RFP-DOCMANAGESOLUTION1 City of Hinesville 115 East ML King Jr Drive Hinesville, GA 31313 Request for Proposal for Digitizing Document Services and Document Management Solution RFP-DOCMANAGESOLUTION1 Closing Date: December 20,

More information

ATTACHMENT 1 SECTION 3 - PROJECT SCHEDULE AND INSTRUCTIONS FOR PROPOSAL SUBMISSION

ATTACHMENT 1 SECTION 3 - PROJECT SCHEDULE AND INSTRUCTIONS FOR PROPOSAL SUBMISSION ATTACHMENT 1 SECTION 3 - PROJECT SCHEDULE AND INSTRUCTIONS FOR PROPOSAL SUBMISSION 3.1. Proposal Due Date and Submittal Process Proposers must submit one (1) original, three (3) additional copies, and

More information

REQUEST FOR PROPOSALS (RFP) For. External Audit Services

REQUEST FOR PROPOSALS (RFP) For. External Audit Services REQUEST FOR PROPOSALS (RFP) For External Audit Services Issued by: Resource Productivity and Recovery Authority April 10, 2017 Expression of Interest Deadline: 12 p.m. (EST) on April 18, 2017 Response

More information

GUILFORD COUNTY PARTNERSHIP FOR CHILDREN REQUEST FOR PROPOSALS

GUILFORD COUNTY PARTNERSHIP FOR CHILDREN REQUEST FOR PROPOSALS GUILFORD COUNTY PARTNERSHIP FOR CHILDREN REQUEST FOR PROPOSALS TITLE: Catering Services, Human Resources Services, Information Technology Services, Outreach Services, Printing Services, Program Evaluation

More information

Request for Proposal PROFESSIONAL AUDIT SERVICES. Luzerne-Wyoming Counties Mental Health/Mental Retardation Program

Request for Proposal PROFESSIONAL AUDIT SERVICES. Luzerne-Wyoming Counties Mental Health/Mental Retardation Program Request for Proposal PROFESSIONAL AUDIT SERVICES Luzerne-Wyoming Counties Mental Health/Mental Retardation Program For the Fiscal Year July 1, 2004 June 30, 2005 DUE DATE: Noon on Friday, April 22, 2005

More information

Request for Proposals

Request for Proposals Request for Proposals Windows Ultrabook Laptops Public Notice West Platte R-II School District is currently seeking bids for Windows Ultrabook Laptops as described in the RFP on the West Platte R-II School

More information

REQUEST FOR PROPOSALS SELECTION OF EXECUTIVE SEARCH FIRM

REQUEST FOR PROPOSALS SELECTION OF EXECUTIVE SEARCH FIRM REQUEST FOR PROPOSALS SELECTION OF EXECUTIVE SEARCH FIRM Submitted By: Florida Memorial University Board of Trustees 15800 N.W. 42 nd Avenue Miami Gardens, FL 33054 Date: November 14, 2017 FLORIDA MEMORIAL

More information

EFFICIENCY MAINE TRUST REQUEST FOR PROPOSALS FOR TECHNICAL SERVICES TO DEVELOP A SPREADSHEET TOOL

EFFICIENCY MAINE TRUST REQUEST FOR PROPOSALS FOR TECHNICAL SERVICES TO DEVELOP A SPREADSHEET TOOL EFFICIENCY MAINE TRUST REQUEST FOR PROPOSALS FOR TECHNICAL SERVICES TO DEVELOP A SPREADSHEET TOOL RFP EM-007-2018 Date Issued: January 31,2017 Closing Date: February 16, 2018-3:00 pm local time TABLE OF

More information

Bristol Regional Wastewater Treatment Plant Arc Flash Study Engineering Services City of Bristol Tennessee RFP 18004

Bristol Regional Wastewater Treatment Plant Arc Flash Study Engineering Services City of Bristol Tennessee RFP 18004 Bristol Regional Wastewater Treatment Plant Arc Flash Study Engineering Services City of Bristol Tennessee March 2018 I. Introduction The City of Bristol Tennessee, herein after referred to as City, is

More information

Internal Connections E-Rate Request for Proposal #E Earlimart School District

Internal Connections E-Rate Request for Proposal #E Earlimart School District Page 1 of 10 Internal Connections E-Rate Request for Proposal #E2018-0002 Earlimart School District Instructions to Vendors Award of this proposal is contingent upon the approval of funding from the Schools

More information

Consultant for Research and Design Services for Equipment and Systems for Unmanned Aerial Vehicle Drone (UAV) for OSU-Cascades

Consultant for Research and Design Services for Equipment and Systems for Unmanned Aerial Vehicle Drone (UAV) for OSU-Cascades INFORMAL REQUEST FOR PROPOSAL No. SF188885P Consultant for Research and Design Services for Equipment and Systems for Unmanned Aerial Vehicle Drone (UAV) for OSU-Cascades PROPOSAL DUE DATE AND TIME June

More information

Request for Proposal

Request for Proposal Request for Proposal ************** Acquisition of Powered Air Purifying Respirators (PAPR) Emergency Medical Task Force Infectious Disease Response Unit May 16, 2016 Southwest Texas Regional Advisory

More information

BIDS MAY BE SUBMITTED BY OR TIME RECORDED MAIL DELIVERY (UPS, FEDEX)

BIDS MAY BE SUBMITTED BY  OR TIME RECORDED MAIL DELIVERY (UPS, FEDEX) FINANCE and ACCOUNTING DEPARTMENT OF GREEN DOT PUBLICS SCHOOLS RFP TITLE: Request for Proposals (RFP) Middle School After School Programs RFP #: 001-2018/19 DATE OF ISSUANCE: April 19, 2018 BIDDER s QUESTIONS

More information

FOR CONSULTING SERVICES FOR DISASTER RESPONSE, ENGINEERING, AND GRANT MANAGEMENT SUPPORT

FOR CONSULTING SERVICES FOR DISASTER RESPONSE, ENGINEERING, AND GRANT MANAGEMENT SUPPORT BRUNSWICK GLYNN COUNTY JOINT WATER & SEWER COMMISION REQUEST FOR PROPOSAL FOR CONSULTING SERVICES FOR DISASTER RESPONSE, ENGINEERING, AND GRANT MANAGEMENT SUPPORT Date Advertised Friday, November 17, 2017

More information

Request for Proposal. Mobile Application for Customer Interface. October 6 th, 2017 Procurement Contact Holly Hussey

Request for Proposal. Mobile Application for Customer Interface. October 6 th, 2017 Procurement Contact Holly Hussey Request for Proposal Mobile Application for Customer Interface October 6 th, 2017 Procurement Contact Holly Hussey supplyandservices@sjenergy.com SAINT JOHN ENERGY OVERVIEW Saint John Energy is an electrical

More information

REQUEST FOR PROPOSALS: AUDIT SERVICES. Issue Date: February 13 th, Due Date: March 22 nd, 2017

REQUEST FOR PROPOSALS: AUDIT SERVICES. Issue Date: February 13 th, Due Date: March 22 nd, 2017 REQUEST FOR PROPOSALS: AUDIT SERVICES Issue Date: February 13 th, 2017 Due Date: March 22 nd, 2017 In order to be considered, proposals must be signed and returned via email to rtan@wested.org by noon

More information

REQUEST FOR PROPOSAL

REQUEST FOR PROPOSAL 1 REQUEST FOR PROPOSAL FOR 3 rd Party Ambulance Billing Services PROPOSAL NO. FY2013/004 BY SPOKANE TRIBE OF INDIANS PURCHASING/PROPERTY DEPARTMENT 6195 FORD/WELLPINIT RD PO BOX 100 WELLPINIT WA 99040

More information

General Procurement Requirements

General Procurement Requirements Effective Date: July 1, 2018 Applicability: Grant Purchasing and Procurement Policy Related Policies: Moravian College Purchasing Policy and Business Travel Policy Policy: This policy provides guidelines

More information

COUNTY OF DUNN, WISCONSIN REQUEST FOR PROPOSALS PROCUREMENT NO CSB CONSTRUCTION MANAGEMENT SERVICES

COUNTY OF DUNN, WISCONSIN REQUEST FOR PROPOSALS PROCUREMENT NO CSB CONSTRUCTION MANAGEMENT SERVICES COUNTY OF DUNN, WISCONSIN REQUEST FOR PROPOSALS PROCUREMENT NO. 2018-19-CSB CONSTRUCTION MANAGEMENT SERVICES The County of Dunn is requesting proposals for Construction Management Services. The services

More information

NEBRASKA ENVIRONMENTAL TRUST BOARD RULES AND REGULATIONS GOVERNING ACTIVITIES OF THE NEBRASKA ENVIRONMENTAL TRUST

NEBRASKA ENVIRONMENTAL TRUST BOARD RULES AND REGULATIONS GOVERNING ACTIVITIES OF THE NEBRASKA ENVIRONMENTAL TRUST NEBRASKA ENVIRONMENTAL TRUST BOARD TITLE 137 RULES AND REGULATIONS GOVERNING ACTIVITIES OF THE NEBRASKA ENVIRONMENTAL TRUST February 2005 1 TITLE 137 RULES AND REGULATIONS GOVERNING ACTIVITIES OF THE NEBRASKA

More information

PROPOSAL INSTRUCTIONS AND REQUIREMENTS

PROPOSAL INSTRUCTIONS AND REQUIREMENTS PROPOSAL INSTRUCTIONS AND REQUIREMENTS A Proposal is requested by the Dallas/Fort Worth International Airport Board (herein called Board). The Board will receive separate sealed Proposals until the deadline

More information

REQUEST FOR PROPOSALS. Design-Build of General Aviation Terminal Building. RFP# AIR/17-012, page 1

REQUEST FOR PROPOSALS. Design-Build of General Aviation Terminal Building. RFP# AIR/17-012, page 1 REQUEST FOR PROPOSALS Design-Build of General Aviation Terminal Building RFP# AIR/17-012, page 1 RFP# AIR/17-012 REQUEST FOR PROPOSALS ISSUE DATE: November 22, 2017 TITLE: DUE: Design-Build of General

More information

TOWN AUDITING SERVICES

TOWN AUDITING SERVICES REQUEST FOR PROPOSAL TOWN AUDITING SERVICES TOWN OF LONGMEADOW MASSACHUSETTS Saved as: RPF Acct Auditing Services FY 12-14 03/1/11 TOWN OF LONGMEADOW REQUEST FOR PROPOSALS FOR AUDITING SERVICES The Town

More information

REQUEST FOR PROPOSAL (RFP) PROJECT MANAGEMENT CEDAR BAND TRAVEL PLAZA ENTERPRISE

REQUEST FOR PROPOSAL (RFP) PROJECT MANAGEMENT CEDAR BAND TRAVEL PLAZA ENTERPRISE REQUEST FOR PROPOSAL (RFP) PROJECT MANAGEMENT CEDAR BAND TRAVEL PLAZA ENTERPRISE PAIUTE INDIAN TRIBE OF UTAH 440 NORTH PAIUTE DRIVE CEDAR CITY, UT 84721 OCTOBER 18, 2017 TABLE OF CONTENTS 1. SUMMARY AND

More information

CITY OF HONDO ENGINEERING REQUEST FOR QUALIFICATIONS

CITY OF HONDO ENGINEERING REQUEST FOR QUALIFICATIONS CITY OF HONDO ENGINEERING REQUEST FOR QUALIFICATIONS The City of Hondo requests the submission of qualifications statements, which will lead to the possible award of a contract to provide planning, design

More information

Copiers. Contact Information: Gordon County Attn: Purchasing Director 201 North Wall Street Calhoun, Georgia 30701

Copiers. Contact Information: Gordon County Attn: Purchasing Director 201 North Wall Street Calhoun, Georgia 30701 Copiers Contact Information: Gordon County Attn: Purchasing Director 201 North Wall Street Calhoun, Georgia 30701 (706) 879-2198 mvaughn@gordoncounty.org Copiers 1 Table of Contents 1.0 Overview... 3 1.2

More information